Maceda v. Development Bank

G.R. No. 174979 & G.R. No. 175010 · 2010-08-11 · J. CARPIO, J.: · Primary: Civil; Secondary: Commercial
REITERATION

Facts

The Antecedents: Bonifacio Sanz Maceda, Jr. obtained a P7.3 million loan from the Development Bank of the Philippines (DBP) in 1976 to finance the expansion of the New Gran Hotel. DBP imposed a condition that it would choose the building contractor, Moreman Builders Co., and that loan releases would be paid directly to the contractor based on verified construction progress. The construction deadline was December 1977. Maceda later filed a complaint against Moreman for rescission of the building contract due to alleged anomalous loan releases and delays, which the court granted in 1978, suspending the loan availment period and allowing Maceda to take over construction. DBP was ordered to release remaining funds to Maceda. Procedural History: Maceda filed a separate case against DBP in 1984 for Specific Performance with Damages, alleging DBP conspired with Moreman in anomalous loan releases and subsequently obstructed Maceda's efforts to complete the hotel by delaying fund releases and imposing onerous conditions. The Regional Trial Court (RTC) ruled in favor of Maceda in 1997, ordering DBP to release loan balances, return improperly collected interest, and pay damages. DBP appealed, and the RTC later amended its decision. The Court of Appeals (CA) initially dismissed both parties' appeals, affirming the RTC's decision. However, a prior petition for certiorari regarding execution pending appeal was granted in DBP's favor, annulling the RTC's order of partial execution, a decision affirmed by the Supreme Court. The Petition: Both Bonifacio Sanz Maceda, Jr. and the Development Bank of the Philippines filed petitions for review under Rule 45 of the Rules of Civil Procedure, assailing the Court of Appeals' decision. Maceda argued that the awarded damages, particularly the cost to complete the hotel, were insufficient and unrealistic given the passage of time. DBP challenged the CA's affirmation of the RTC's findings, questioning its liability for Moreman's actions, the alleged connivance with the contractor, the reasonableness of stopping loan releases, and the excessiveness of the awarded damages.

Issue(s)

Whether the Court of Appeals erred in holding DBP liable for the acts of Moreman Builders and whether DBP connived with Moreman Builders in the alleged anomalous loan releases. Whether there was reasonable ground for DBP to stop the loan releases. Whether the Court of Appeals erred in upholding the trial court's imposition of interest on the unreleased portion of the loan and for the return of interests paid on the loan already released to Maceda. Whether the damages awarded in favor of Maceda are unreasonable and excessive. Whether the trial court and appellate court erred in ordering DBP to pay Maceda the cost to finish the hotel instead of releasing the loan balance.

Ruling

The Supreme Court granted the petitions, affirming with modification the decision of the Court of Appeals. DBP was ordered to pay Maceda ₱6,153,398.05 as actual damages, with 6% interest per annum from the filing of the complaint. DBP was also ordered to pay Maceda ₱700,000 as moral damages, ₱150,000 as exemplary damages, ₱500,000 as temperate damages, and ₱100,000 as attorney's fees. The total awarded amount shall earn 12% interest per annum from finality of judgment until full satisfaction.

Ratio Decidendi

On the issue of DBP's liability for Moreman's acts and connivance: The Court affirmed the findings of the lower courts that DBP actively connived with Moreman in anomalous loan releases. Evidence showed that checks were drawn solely in Moreman's name, and Maceda's conformity was solicited after the fact. DBP improperly discharged its duty as a verifier by allowing exaggerated charges and contributing to the swindling of Maceda. Furthermore, DBP was at fault for not releasing the approved ₱1.003 million and the substantial unreleased balance of ₱1,952,489.10, which contributed to construction delays and increased costs. On the issue of DBP's grounds for stopping loan releases: The Court found that DBP's actions, including giving the impression of non-support and verbally advising suppliers to pull out, and refusing payment to suppliers after Maceda took over, were detrimental to the project. These actions, coupled with the delay in releasing funds, provided no reasonable ground for DBP to halt releases and instead demonstrated DBP's fault. On the issue of interest on unreleased loan portions and return of paid interests: The Court found that DBP was at fault for delaying the release of the loan. The trial court's order to pay interest on the ₱1.003 million portion from January 1978 and to return ₱797,988.95 in interest/charges was affirmed, as these were consequences of DBP's own delays and improper actions. On the issue of damages awarded: The Court found the awarded amounts for moral damages (₱700,000), exemplary damages (₱150,000), temperate damages (₱500,000), and attorney's fees (₱100,000) to be appropriate and not unconscionable or exorbitant under the circumstances. On the issue of ordering DBP to pay the cost to finish the hotel versus releasing the loan balance: The Court modified the ruling, finding that ordering DBP to pay ₱17,547,510.90 to finish the hotel was an error. In an action for specific performance, the party at fault should perform its undertaking. However, after more than 30 years, implementing the loan agreement as written became impossible due to rising costs and market changes. Therefore, the Court deemed it equitable to rescind DBP's obligation to deliver the loan balance. Instead, DBP was ordered to pay Maceda the value of his cash equity infusion, ₱6,153,398.05, as actual damages, plus applicable interest.

Main Doctrine

In an action for specific performance of a loan agreement, where it becomes impossible to implement the agreement as originally written due to the passage of time and changed market conditions, the court may rescind the obligation to deliver loan proceeds and, in lieu thereof, order the creditor to pay the debtor the value of the debtor's equity infusion as actual damages, plus applicable interest.

Access audio review, related cases, codal links, and more.

Open LexMatePH →